home
***
CD-ROM
|
disk
|
FTP
|
other
***
search
/
Shareware Overload Trio 2
/
Shareware Overload Trio Volume 2 (Chestnut CD-ROM).ISO
/
dir33
/
gde757_1.zip
/
LHARC1.EXE
/
2680.BLD
< prev
next >
Wrap
Text File
|
1993-01-06
|
5KB
|
252 lines
#2680
@001 Enter the name of the OWNER:
@002 Enter the name of the CONTRACTOR:
@100 Enter the description of the work to be performed:
@101 Enter estimated completion schedule:
!102 Enter the contract price:
#2681 Do you want to specify materials to be used?
#if#2681
@300 Specify areas specified:
@301 Enter specifications:
#endif
#2682 Will the contractor pay for permits?
#2683 Will contractor be required to name subcontractors?
#2684 Will contract be required to provide proof of insurance?
#if#2684
!103 Enter insurance limits required (in numerals):
#endif
#2685/#2686/#2687
1/3 Rough in;1/3 inspection;1/6;1/6
Weekly draw on per centage of completion
Joint checks on materials; 1/3;1/3- 1/6,1/6 on labor
#2688 Is contractor required to remove trash?
#2689 Is mechanic's lien clause desired?
#2690 Is arbitration clause for disputes desired?
#2691 Is definition for termination required?
#2692 Is attorney's fee clause desired?
#2693
#end control section
#2680
/* Para. 2680: Contract for remodeling, large */
CONTRACTING AGREEMENT
@001, referred to as OWNER, and @002, referred to as CONTRACTOR,
agree as follows:
CONTRACTOR shall perform the following services for OWNER:
@100
on the following estimated schedule:
@101
for the following price: $ @102 (!102 dollars)
Contractor shall be responsible for the following in addition to
the workman like performance of the work stated above:
#2681
/* Para 2681: Spec of materials */
The materials used for the following areas:
@300
shall meet the following respective specifications, or be
equivalent to the following manufacturer's product lines
described:
@301
#2682
/* Para 2682: Permits */
Provision of all permits required for the services to be performed
above.
#2683
/* Para.2683: Subs */
CONTRACTOR shall at least 7 days prior to commencement of work
provide the names and addresses of all sub-contractors intended
to be utilized in the construction. At the time of each payment
of any portion of the contract price, the CONTRACTOR shall
provide a lien waiver or certificate of payment for all work
performed by each sub-contractor.
#2684
/* Para 2684: Insurance*/
Provision of worker's compensation insurance, general liability
insurance in a minimum amount of $ @103 (!103 dollars).
#2685
/* Para. 2685: Draw sked */
The stipulated contract price shall be paid as follows:
1/3 on rough in; 1/3 on first inspection and 1/6 on final
inspection and 1/6 on final inspection and completion of all
appearance/punch list in items.
#2686
/* Para. 2686: Weekly draw based on per centage of completion*/
The stipulated contract price shall be paid as follows:
A weekly draw based upon per centage of completion, less a
retainage of 10% per cent, which shall be paid on final
inspection and completion of appearance/punch list items.
#2687
/* Para. 2687: Bills for materials */
The stipulated contract price shall be paid as follows:
When bona fide bills for materials are presented the same shall
be paid directly by the OWNER within the terms provided. Labor
shall be paid as follows:
1/3 on rough in; 1/3 on inspection; 1/6 on completion; 1/6 on
final inspection and completion of appearance/punch list items.
#2688
/* Para. 2688: Removal of trash */
The CONTRACTOR shall daily remove all trash and debris from the
premises.
#2689
/* Para. 2689: Ack lien */
The owner acknowledges an express mechanic's lien on the above
described real estate to secure the payment of the amounts
contracted herein.
#2690
/* Para. 2690: Arb */
Any disputes arising out of or related to this agreement shall be
arbitrated under the rules of the American Arbitration Association
before a single arbiter.
#2691
/* Para. 2691: Termination */
This agreement may be terminated by OWNER upon substantial
abandonment of the project, defined as at least 3 business days
without substantial activity, except delays caused by:
a) bona fide weather disturbances;
b) strikes;
c) shortages of material;
d) sub contractor delays not caused by the general contractor;
e) governmental delays except those caused by the fault of
contractor or subcontractor;
or,
persistent failure of workmanship to meet high quality standards
for which adequate assurance of correction is not provided.
#2692
/* #2692: Attorney's fee clause*/
In any disputes related to this agreement, the adjudication body
may assess reasonable counsel fees to the prevailing party.
#2693
/* Para. 2693--- closer */
This is the entire agreement between the parties and this
agreement may only be altered in writing.
Dated: _________________________
____________________________________________________
@001
____________________________________________________
@002